AGREEMENT FOR WEBSITE PROJECT & ESTIMATE #1234
PROJECT NAME: Update Website
Between The Big Truck Co., and My Computer Solutionz
My Computer Solutionz will be referred to as "We" or the "Designer" in this document.
The Big Truck Co./BOB FIELDS / The receiver of service will be referred to as "You" the "Customer" or "Client" in this document.
Prepared 11/8/2019 by My Computer Solutionz
SCOPE OF WORK
My Computer Solutionz will develop a semi-customized website for The Big Truck Co.. The goals of this website are as follows:
1. goals here
2. goals here
3. goals here
4. goals here
The website will be approximately a 5-page website consisting of the following pages: EDITS ONLY.
Scope of Work to include....
TERMS & CONDITIONS
All information in this proposal is subject to the following Website Design Terms & Conditions as well as our General Terms & Conditions.
Client Content means all materials, writing, images, or other creative content provided by Client used in preparing or creating the Deliverables.
Third Party Materials means proprietary third party materials which are incorporated into the Final Deliverables, including without limitation stock photography or illustration.
Designer Tools means all design tools developed and/or used by Designer in performing the Services, including pre-existing and newly developed software including source code, Web authoring tools, type fonts, and application tools, together with any other software or other inventions whether or not patentable, and general non-copyrightable concepts such as website design, architecture, layout, navigational and functional elements.
The design process consists of three phases: "Concept, Design & Placement, and Technical/Testing."
1. Concept Phase. The outline of the basic framework or "blueprint" is discussed and drawn out. We will help you develop goals and a site-map if needed.
2. Design Phase. Pages and Menus are created, a template is chosen and installed, colors and styles are added, and sample text/images are put in place. The Client will need to approve or decide on a theme during this phase.
3. Placement Phase.
The Client's responsibility during the beginning two phases is creating/gathering the copy (text) and images for the website. Placement begins when I have received the copy, images, and any fees due for this phase.
3. Technical & Testing Phase. I enable any add-ons for additional functionality that we've agreed upon in our detailed estimate: SEO, analytics, enable security and spam protection, fix any domain issues; add interactive functionality like forms, emails, and final additions. We can make changes to the menu, simple design tweaks, and changes to text and images at this time.
The Client's responsibility: Testing consists of checking the entire website to make sure it is operating as expected and allowing you and your team to provide feedback for any final changes.
A "Working Website" begins at the beginning of the Technical & Testing Phase and a final invoice will be sent, due at the end of the 30-day Testing period.
You can expect Your website to work in all major web browsers and be mobile-friendly!
Below you will find a more detailed description of the project phases, timeline, due dates, deliverables and fees. You will also find a set of Terms and Conditions.
WORK PLAN & MILESTONES
Milestones are encompassing goals while Deliverables are specific tasks. The Deliverables are due by the Designer (or Client) on the Due Date. Any Fees are due by BOB FIELDS on the same Due Date.
The table below outlines the work process Phases, Milestones, Due Dates, Deliverables, and Fees needed to complete this project. This process is designed to ensure project efficiency and Your complete satisfaction.
Fees are broken down into three parts to keep your project moving forward and are intended to benefit both the Client and Designer. Please see the Website Design Terms & Conditions for details.
Information Architecture/Site map
Signed contract and initial deposit
Design template first draft
Basic page design
Fonts, colors and menu placement
Design in WordPress, html, css
Create contact and/or special forms (plug-ins/html/css)
Client provides all images and copy
Swapping out sample text and images for final Client text and images
Changes to template if needed
Changes to colors/menu
HTML / CSS Template
Design in html/css
Contact form in html/css
Technical & Test Phase
Server & domain setup
Enable security & spam protection
Move site to live environment
Incorporate feedback from Team
COST ESTIMATE DETAILS
Please refer to your Estimate for itemized costs (sent in a separate message).
To adhere to the timeframe above, My Computer Solutionz agrees to provide the deliverables on time or else provide an updated timeframe with a written notice for the delay acceptable to the Client.
The Big Truck Co., likewise, agrees to shall use all reasonable efforts to provide needed information, materials, approvals or feedback within 1 (one) week of receiving the set Deliverables or else provide a written notice for the delay acceptable to the Designer.
If either party is delayed more than 1 (one) month and no accepted agreement is made, this contract will be considered void and the balance for the work performed at that milestone will be due in full (or the Designer will be obligated to complete the current Milestone paid for by the Customer).
General Delays. Any delay caused by conditions beyond the reasonable control of the parties shall not be considered a breach and will result in a day-for-day extension on any performance due. Each party shall use reasonable efforts to notify the other party, in writing, of a delay. Conditions beyond the reasonable control of the parties include, but are not limited to, natural disasters, acts of government after the date of agreement, power failure, severe illness, fire, flood, acts of God, labor disputes, riots, acts of war, terrorism, and epidemics.
Since much of our communication will happen online, My Computer Solutionz commits to providing best-in-class communication.
To this end, we will use less email and more of a task platform such as Asana or Dropbox Paper. While email can be a great way to communicate, messages and replies get lost and confusing.
We ask that you help by using the chosen platform.
You will be sent information on how to communicate through Asana or Paper. Our intent is to keep us on track and not to make things more difficult for you. If you receive too many (or too little) messages from us, please let us know.
The Terms of this Agreement expire 30 days after being submitted to Client. If this Agreement expires, Designer may modify the Agreement and resubmit it to Client.
Fees. Client agrees to pay Designer the fees listed in the Project Proposal, including all taxes.
Additional Costs. Pricing in the Project Proposal includes only Designer fees. Any other costs, such as hosting, art licensing, or photography, will be billed to Client.
Hosting Final Deliverables. Designer will host the Final Deliverables on Designer's web space while the Project is under construction. If the Final Deliverables are not completed by the completion date listed in the Project Proposal, and the delay is not caused by Designer, Client agrees to pay Designer $12.99 per month for hosting until the Final Deliverables are moved to Client's server.
Payment is due when Designer completes each milestone as listed in the Work Plan and Milestones schedule and Client accepts the Deliverables for that milestone.
Invoices: All invoices are payable within 14 days of receipt. Invoices shall list any expenses and additional costs as separate items.
Delay. Designer may suspend work if Milestone fees are not paid by the due date.
Late Fee. A monthly service fee of 1.5 percent, or the maximum allowed by law, is payable on all overdue balances.
Crediting Late Payments. Payments will be credited to late payments first, then to unpaid balances.
Collection Expenses. Client shall pay all collection or legal fees caused by late payments.
Withholding Delivery. Designer may withhold delivery and transfer of ownership of any current work if accounts are not current or overdue invoices are not paid in full.
Withholding License. All grants of any license to use or transfer ownership of any intellectual property rights under this Agreement are conditioned on full payment, including all outstanding Additional Costs, Expenses, Fees, or any other charges.
CHANGES TO PROJECT SCOPE
Change Request. If Client wants to change the Scope of Work after acceptance of this Agreement, Client shall send Designer a written Change Order describing the requested changes in detail. Within five business days of receiving a Change Order, Designer will respond with a statement proposing Designer's availability, additional fees, changes to delivery dates, and any modification to the Terms and Conditions. Designer will evaluate each Change Order at its standard rate and charges.
Major Change. If Client requests are at or near 50% of the time required to produce Deliverables, or the value of the Scope of Services, Designer shall be entitled to submit a new and separate Proposal to Client for written approval. Designer shall not begin work on the revised services until he receives a signed revised proposal and any additional fees.
Minor Change. If Client requests are not Major Changes, Client will be billed on a time and materials basis at Designer's hourly rate of $65 per hour. Such charges shall be in addition to all other amount payable under this Agreement, despite any maximum budget, contract price, or final price identified. Designer may extend or modify any delivery schedule or deadlines in the Agreement as may be required by such changes.
Acceptance/Rejection. Client will have five business days to respond in writing accepting or rejecting the new proposal. If Client rejects the proposal, Designer will not be obligated to perform any services beyond those in the original Agreement.
EVALUATION AND ACCEPTANCE
Testing. Designer will test and correct Deliverables using commercially reasonable efforts before providing Deliverables to Client.
Approval Periods. Within five business days after receiving each Deliverable, Client shall notify Designer in writing of any failure to comply with the specification of the Project Proposal or of any other objections, corrections, or changes required. Within five business days of receiving Client's notification, Designer shall correct and submit a revised Deliverable to Client. Within five business days of receiving a revised Deliverable, Client shall either approve the corrected version or make further changes. If after five corrections by Designer Client finds the Deliverables are not acceptable, Client may terminate this agreement subject to the termination clauses of this Agreement. If Client fails to provide approval or comments during any approval period, those Deliverables will be considered approved and accepted. All objections, corrections, and changes shall be subject to the terms and conditions of this Agreement.
Client acknowledges that he or she is responsible for performing the following in a reasonable and timely manner within one (1) week unless otherwise agreed: (a) Provide Client Content in a form suitable for use in the Deliverables without further preparation by Designer, unless otherwise specified in the Project Proposal. This includes cropping and resizing images for best-in-practice website standards; (b) Proofread all Content and Deliverables. Client will be charged for correcting errors after the acceptance of any Deliverable; (c) Make decisions regarding other parties.
ACCREDITATION AND PROMOTION
Accreditation. Designer shall be entitled to place accreditation, as a hyperlink or otherwise, in the form, size, and location as incorporated by Designer in the Deliverables on each page of the Final Deliverables.
Promotion. Designer retains the right to reproduce, publish, and display the Deliverables in Designer’s portfolios and websites, in galleries, design periodicals, and other media or exhibits for the purposes of recognition of creative excellence or professional advancement, and to be credited with authorship of the Deliverables in connection with such uses.
Promotional Approval. Either party, subject to the other’s reasonable approval, may describe its role in the Project on its website and in other promotional and marketing materials, and, if not expressly objected to, include a link to the other party’s website.
Client’s "Confidential Information" includes information that Designer should reasonably believe to be confidential, including "trade secrets" or information not typically known to a competitor, for example.
Designer's "Confidential Information" includes the source code of any Designer Tools.
All material considered confidential by either party shall be designated as confidential. Confidential Information shall not be disclosed to third parties and shall only be used as needed to perform this Agreement. Confidential Information shall not include any information that is already known by the recipient, becomes publicly known through no fault of the recipient, or is received from a third party without a restriction on disclosure.
RELATIONSHIP OF THE PARTIES
Independent Contractor. Designer is an independent contractor. Designer shall have sole discretion in determining the manner and means by which the Services are accomplished. No agency, partnership, joint venture, or employee-employer relationship is intended or created by this Agreement. Neither party is authorized to act as agent or bind the other party except as expressly stated in this Agreement. Designer and the work product, or Deliverables prepared by Designer, shall not be deemed a work for hire as defined under Copyright Law. All rights granted to Client are contractual in nature and are expressly defined by this Agreement.
Design Agents. Designer shall be allowed to use third parties as independent contractors in connection with the Services (“Design Agents”). Designer shall remain fully responsible for Design Agents’ compliance with this Agreement.
No Exclusivity. This Agreement does not create an exclusive relationship between the parties. Client is free to engage others to perform services of the same or similar nature to those provided by Designer, and Designer shall be entitled to offer and provide design services to others, solicit other clients, and otherwise advertise the services offered by Designer.
RIGHTS TO DELIVERABLES OTHER THAN FINAL ART
Client Content. Client Content is the exclusive property of the Client. Client grants Designer a nonexclusive, nontransferable license to use, reproduce, modify, display and publish the Client Content solely in connection with Designer’s performance of the Services and limited promotional uses of the Deliverables as authorized in this Agreement.
Preliminary Works. Designer retains all rights in and to all Preliminary Works. Client shall return all Preliminary Works to Designer within 30 days of completion of the Services.
Designer Tools. All Designer Tools are and shall remain the exclusive property of Designer. Designer grants Client a nonexclusive, nontransferable, perpetual, worldwide license to use the Designer Tools solely to the extent necessary with the Final Deliverables for the Project.
Final Deliverables. The Final Deliverables become the exclusive property of the Client once the project is paid in full and at the Go-Live Date. The only exception is that of copy-written material with granted access by a third party. These materials are subject to their copyrights. This includes WordPress core files which are copy-written by WordPress.
During the first 90_days following expiration of this Agreement, Designer shall provide up to 12 hours of Support Services at no additional cost to Client. Support Services means commercially reasonable technical support and assistance to maintain and update the Deliverables, including correcting any errors or deficiencies.
Requests for additional support will be billed on a time and materials basis at Designer's standard rate.Training on how to use WordPress or other features is not the intent of this warranty period.
Additional Training: Following our "Soft" Go-Live Date, Designer has built in the following amount of training on how to efficiently use your product: 2 hours which must be utilized within 12_months from the "Soft" Go-Live Date.
Maintenance Period: After the Warranty Period expires and at Client’s option, Designer will provide Support Services for the following (12) twelve months for a monthly fee of Designer’s hourly fees of $65 per hour, or as negotiated in a separate contract.
No Enhancements: The services in the Warranty Period and the Maintenance Period do not include enhancements to the Project or other services outside the scope of the Proposal.
During the Maintenance Period, Client may request that Designer develop enhancements to the Deliverables. Designer shall exercise commercially reasonable efforts to prioritize Designer’s resources to create such enhancements. Client understands Designer may have preexisting obligations that may delay requested enhancements. Designer shall provide any enhancements shall be provided on a time and materials basis at Designers standard rate.
Alterations: Alteration of any Deliverable is prohibited without the express permission of Designer. Designer will be given the first opportunity to make the required alterations. Unauthorized alterations shall constitute additional use and will be billed accordingly.
REPRESENTATIONS AND WARRANTIES
By Client: Client represents and warrants to Designer that: (a) To the best of Client’s knowledge, use of the Client Content does not infringe upon the rights of any third party; (b) Client shall comply with the terms and conditions of any licensing agreements which govern the use of Third Party Materials; (c) Client will obtain all necessary and appropriate rights and licenses to grant license to Designer to use Third Party Materials.
By Designer: Designer represents and warrants to Client that: (a) Designer will provide the Services identified in the Agreement in a professional and workmanlike manner; (b) Designer shall secure all necessary rights, title, and interest in and to the Final Deliverables, including Designer Tools, sufficient for Designer to grant the intellectual property rights provided in this Agreement; (c) To the best of Designer’s knowledge, the Deliverables will not violate the rights of any third parties; (d) If Client or third parties modify the Deliverables or use the Deliverables outside of the scope or purpose of this Agreement, all representations and warranties of Designer shall be void.
EXCEPT FOR THE EXPRESS REPRESENTATIONS AND WARRANTIES STATED IN THIS AGREEMENT, DESIGNER MAKES NO WARRANTIES WHATSOEVER. DESIGNER EXPLICITLY DISCLAIMS ANY OTHER WARRANTIES OF ANY KIND, EITHER EXPRESS OR IMPLIED, INCLUDING BUT NOT LIMITED TO WARRANTIES OF MERCHANTABILITY OR FITNESS FOR A PARTICULAR PURPOSE OR COMPLIANCE WITH LAWS OR GOVERNMENT RULES OR REGULATIONS APPLICABLE TO THE PROJECT.
INDEMNIFICATION AND LIABILITY
By Client: Client shall indemnify Designer from any and all damages, liabilities, costs, losses, expenses, or attorney fees arising out of any claim, demand, or action by a third party arising out of any breach of Client’s responsibilities or obligations, representations, or warranties under this Agreement. Designer shall promptly notify Client in writing of any third party claim or suit. Client shall have the right to fully control the defense and any settlement of such claim or suit.
By Developer: In the case of a third party lawsuit or proceeding based on a claim that Deliverables breach the third party’s intellectual property rights, and it is determined that such infringement has occurred, Designer may at his own expense replace any infringing content with non-infringing content.
Limitation of Liability: THE SERVICES AND THE WORK PRODUCT OF DESIGNER ARE SOLD “AS IS.” IN ALL CIRCUMSTANCES, THE MAXIMUM LIABILITY OF DESIGNER, ITS DIRECTORS, OFFICERS, EMPLOYEES, DESIGN AGENTS, AND AFFILIATES (“DESIGNER PARTIES”) TO CLIENT FOR DAMAGES FOR ANY AND ALL CAUSES WHATSOEVER, AND CLIENT’S MAXIMUM REMEDY, REGARDLESS OF THE FORM OF ACTION, WHETHER IN CONTRACT, TORT OR OTHERWISE, SHALL BE LIMITED TO THE NET PROFIT OF DESIGNER. IN NO EVENT SHALL DESIGNER BE LIABLE FOR ANY LOST DATA OR CONTENT, LOST PROFITS, BUSINESS INTERRUPTION, OR FOR ANY INDIRECT, INCIDENTAL, SPECIAL, CONSEQUENTIAL, EXEMPLARY OR PUNITIVE DAMAGES ARISING OUT OF OR RELATING TO THE MATERIALS OR THE SERVICES PROVIDED BY DESIGNER, EVEN IF DESIGNER HAS BEEN ADVISED OF THE POSSIBILITY OF SUCH DAMAGES, AND NOTWITHSTANDING THE FAILURE OF ESSENTIAL PURPOSE OF ANY LIMITED REMEDY.
TERM AND TERMINATION
Term: This agreement shall begin when both parties sign and shall continue until all Services are complete and delivered, or until the Agreement is Terminated.
Termination for Cause: Either party may terminate this agreement at any time with a seven-day prior written notice if the other party breaches any of its material responsibilities or obligations under this Agreement and fails to cure that breach during that seven-day period.
Termination for Insolvency: Either party may terminate this agreement at any time, with written notice to the other party, if the other party ceases to conduct business in its normal course; makes an assignment for the benefit of creditors; is liquidated or otherwise dissolved; becomes insolvent; files a petition in bankruptcy; or a receiver, trustee, or custodian is appointed for it.
Termination by Mutual Agreement: This agreement may be terminated by the mutual agreement of the parties.
Termination for Convenience: Either party may terminate this agreement at any time and for any reason on seven-day prior written notice to the other party. If Client terminates the Agreement under this section, Designer shall, at Clients reasonable discretion, complete any work assigned or scheduled during the notice period in accordance with the terms and conditions of this Agreement.
Termination Fees: In the event of termination, Client shall pay Designer for the Services performed through the date of termination in the amount of a prorated portion of the fees due. Client shall pay all Expenses, Fees, and Additional Costs incurred through the date of termination.
Intellectual Property: If Client terminates and on full payment of compensation, Designer grants Client right and title as provided by this Agreement with respect to those Deliverables provided and accepted by Client as of the date of termination.
Confidential Information: On expiration or termination of this Agreement: (a) each party shall return or, at the disclosing party’s request, destroy the Confidential Information of the other party, and (b) all rights and obligations regarding Confidential Information shall survive.
RIGHTS TO FINAL ART
License: Designer grants to Client a non-exclusive, perpetual and worldwide license to use and display the Final Deliverables in accordance with this Agreement. The rights granted to Client are for use of the Final Deliverables in its original form only. Client may not change, create derivative works or extract portions of the Final Deliverables.
Liquidation for Unlicensed use: Additional use of any Deliverables by Client outside the scope of the license granted above requires additional fees. Designer shall be entitled to further compensation equal to 75% of the total original Project fee unless otherwise agreed in writing by both parties. In the event of non-payment, Designer shall be entitled to pursue all remedies under law and equity.
Negotiation: Parties agree to attempt to resolve any dispute by negotiation between the parties.
Arbitration/Mediation: If parties are unable to resolve the dispute by negotiation, either party may start mediation and/or binding arbitration in a forum mutually agreed to by the parties.
Litigation: In all other circumstances, the parties specifically consent to the local, state and federal courts located in Guilford County in the state of North Carolina. The parties waive any jurisdictional or venue defenses available to them and further consent to service of process by mail.
Attorney Fees: The prevailing party shall be entitled to recover its attorneys’ fees and costs in any dispute resolved by binding arbitration or litigation.
Modification/Waiver: Modifications to this Agreement must be in writing and signed by both parties. Failure by either party to enforce any right or seek to remedy any breach under this Agreement shall not be construed as a waiver of such rights nor shall a waiver by either party of default in one or more instances be construed as constituting a continuing waiver or as a waiver of any other breach.
Notices: All notices under this Agreement shall be given in writing either by: (a) Email, with return confirmation of receipt; (b) Certified or Registered mail, with return receipt requested. Notice will be effective when received, or in the case of email, on confirmation of receipt.
No Assignment: Rights or obligations under this Agreement shall not be transferred, assigned or encumbered without the prior written consent of the other party.
Governing Law: This Agreement shall be governed by the law of North Carolina, in the County of Guilford.
Severability: If any provision of this Agreement is held invalid or unenforceable, the remainder of this Agreement shall remain in full force and effect. Where possible the invalid or unenforceable provision shall be interpreted in such manner as to be effective and valid under applicable law.
Headings: Headings and numbering used in this Agreement are for convenience and reference only and shall not affect the scope, meaning, intent or interpretation of this Agreement, and shall not have any legal effect.
Complete Agreement: This Agreement is the entire understanding of the parties and supersedes all prior understandings and documents relating to the subject matter of this Agreement.
GENERAL TERMS & CONDITIONS
CONSENT TO DO BUSINESS ELECTRONICALLY
My Computer Solutionz and The Big Truck Co. consent to do business electronically. This includes, but is not limited to: Disclosures, sending and receiving feedback, contracts, agreements, and electronic signatures. Electronic business may be conducted by e-mail, websites, live and recorded video and audio, screen sharing between Client and Designer, fax, platforms similar to dropbox to share files, and platforms similar to Asana and Paper that allow collaboration.
The Client's signature below authorizes Designer to begin work, indicates the information and terms in this proposal are to Clients satisfaction and approval, and agrees to the Terms and Conditions.
To sign electronically, sign just ABOVE THE BOTTOM SOLID LINE & CLICK SAVE. Please sign using a stylus, mouse, or finger. After the document is signed, you can proceed to print or save as a PDF.
To sign by printing, print this document, sign ABOVE "CLIENT SIGNATURE" and return a signed copy of this Project Proposal to My Computer Solutionz. You will receive a copy back of the fully-signed Proposal.
Print Designer Name
Print Client Name
Fill out the information below, Sign and Click Save Signature! You can then click "Print Contract" for your records.